Terms and Conditions of Sale


Terms and Conditions of Sale - ARTeSYN Biosolutions USA LLC

This document constitutes an offer to sell the goods and services specified. This offer is expressly limited to the acceptance of the terms contained herein and constitutes notice of objection to any additional or different terms in the acceptance as to preclude the inclusion of any different or additional terms in any resulting contract.

1. Payment Terms

(a) All prices set forth herein are for ARTeSYN shipping point and are payable at 30days, after the invoice date. Shipments will be invoiced as of the date of shipment, and all accounts not paid within thirty (30) days of invoice date will bear interest at the rate of one-half percent (1½)% per month from invoice date. In the event of failure of timely payment by Buyer, Buyer shall pay to ARTeSYN all costs of collection including fifteen percent (15%) of the amount due hereunder as attorney’s fees if collected by or through an attorney-at-law.

(b) Prices on the goods are exclusive of all city, state and federal exercise taxes, including, without limitation, taxes on manufacture, sales, receipts, gross income, occupation use and similar taxes. Wherever applicable, any tax or taxes will be added to the invoice as a separate charge to be paid by the Buyer,

(c) In addition to the purchase price for the goods Buyer shall pay and be liable for all Buyer’s expenses incurred by ARTeSYN for insurance, freight, cartage, warehousing and all other charges in connection with loading and shipping the goods to the buyer.

(d) Buyer shall pay amounts payable to ARTeSYN hereunder when due, time being of the essence.

(e) Payment for the goods shall, if ARTeSYN so requires, be made in full prior to delivery and ARTeSYN shall be entitled to withhold delivery until such payment has been made and to any check or other negotiable instrument given in payment has cleared. ARTeSYN shall have the additional right at any time to limit or cancel any credit extended or to be extended hereunder, Upon failure by Buyer to make payment to ARTeSYN within thirty (30) days after notice from ARTeSYN limiting or canceling any credit extended or requiring Buyer to make payment before delivery, ARTeSYN shall have the option to cancel this and other contracts between ARTeSYN and Buyer. In such an event, in addition to its other remedies, ARTeSYN may resell all or any part of the goods undelivered under contract without notice of public or private sale and Buyer shall be liable to ARTeSYN for the difference between the resale price and the price at which Buyer agreed to buy the goods together with incidental damages.

 

2.     Title to and Reservation of Security Interest in the Goods

(a) Until Buyer has completed payments for the goods, title, and ownership to said goods shall remain with ARTeSYN and its assigns, and ARTeSYN hereby reserves and Buyer hereby grants to ARTeSYN a purchase money security interest in the goods. The goods shall at all times be located at the place to which delivery is to be made as indicated on the reverse hereof unless written approval is obtained from ARTeSYN for removal to some other place. Said goods shall not become part of the realty.

(b) If the buyer defaults in the payment of any part of the purchase price as herein provided at any maturity date as to any payment or fails to comply with or defaults in any of the material provisions of the Agreement, or in the event that a petition for a receiver or in reorganization or in bankruptcy is filed by or against Buyer, or whenever ARTeSYN or its assigns shall deem themselves insecure, then in any such event the full amount of the purchase price remaining unpaid shall become immediately due and payable at the option of the ARTeSYN or its assigns, and the Buyer agrees to return said goods on demand, and ARTeSYN or its assigns may without notice of demand and on demand and without any legal process enter into any premises where the goods are located to take immediate possession thereof and to make such disposition deemed by ARTeSYN or its assigns as desirable. All payment made shall be retained as liquidated damages for the use of the goods and not as penalty. The goods may be sold with or without notice at public or private sale, with the right in ARTeSYN or its assigns to bid in such sale, and the proceeds thereof less expense shall be credited to the amount unpaid. The Buyer agrees to pay the balance forthwith as liquidated damages for the breach of this Agreement.

(c) Until payment for the goods has been completed, Buyer may not sell, transfer, convey, pledge, hypothecate or otherwise use the goods as security for any borrowing or for any other purposes.

 

3.     Insurance

Buyer shall specifically insure the goods against “all risks”, subject to normal exclusions, from the time, that the risk of loss passes to Buyer, during transit, during unloading, and continuously thereafter until all amounts payable by Buyer are paid in full to ARTeSYN for no less than the total amount owing to ARTeSYN with loss first payable to ARTeSYN, as its interest may appear. Evidence of such insurance satisfactory to ARTeSYN shall be submitted by the Buyer prior to shipment or ARTeSYN may procure such insurance at Buyer’s expense.

 

4.     Warranties

(a) ARTeSYN warrants the goods to be free from defects in workmanship and/or materials for a period of one (1) year from the date of shipment to Buyer. This warranty does not extend to parts or components not manufactured or processed by ARTeSYN, although ARTeSYN will to the extent possible pass to Buyer the benefit of any guarantee or warranty given to ARTeSYN in respect of such parts or components. No goods may be returned without the express prior written approval of ARTeSYN after a determination by ARTeSYN that such  goods are defective because of poor workmanship or defective materials. ARTeSYN shall credit or make an adjustment to the purchase price of the goods or replace or repair, at sole option and expense, any defective goods or portions thereof. In the event that the ARTeSYN determines in its sole discretion that the defect is attributable to any cause other than poor workmanship or defective materials (including, but not limited to, misuse or abusive operation of the goods), then ARTeSYN shall have no obligation whatsoever with respect to repair or replacement of the defective goods and the warranty described herein shall be void and of no force and effect.

(b) EXCEPT AS NOTED IN PARAGRAPH 4 (a), THE PARTIES AGREE THAT THERE IS NO WARRANTY OF MERCHANTABILITY OF OR FITNESS FOR A PARTICULAR PURPOSE OR ANY OTHER WARRANTIES BY SELLER, EITHER EXPRESSED OR IMPLIED, OR ANY AFFIRMATION OF FACT OR REPRESENTATION WHICH EXTENDS BEYOND THE DESCRIPTION OF THE FACE HEREOF.

(c) The maximum damages recoverable in the event of a breach of any warranty by ARTeSYN, expressed or implied or of this Agreement shall be limited to the purchase price of the goods. BUYER AGREES THAT NO OTHER REMEDY (INCLUDING, BUT NOT LIMITED TO, INCIDENTAL OR CONSEQUENTIAL DAMAGES FOR LOST PROFITS, LOST SALES, OR ANY INCIDENTAL OR CONSEQUENTIAL LOSS) SHALL BE AVAILABLE TO IT UNDER ANY CIRCUMSTANCES.

 

5.     Delay or Nonperformance

ARTeSYN shall not be liable for delay in shipment for any cause beyond its reasonable control, nor shall such delay entitle Buyer to cancel any order or refuse to accept delivery. ARTeSYN shall not be liable for failure or delay in shipment or other performance hereunder if such failure is due in whole or in part to strikes, fires, accidents, wars, rebellions, civil commotion or public strike, acts of any government, whether legal or otherwise, acts of public enemies, force majeure, inability to secure or obtain or delay in securing or obtaining transportation, machinery, materials, or sufficient qualified labor, or any other causes beyond ARTeSYN reasonable control.

 

6.     Risk or Loss

Unless otherwise specifically agreed in writing, risk of loss of the goods shall pass from ARTeSYN to Buyer when the goods or any portion thereof, properly packed and secured in such a manner as to reach their destination in good condition under normal conditions of transport, are placed in the possession of the carrier, FOB ARTeSYN shipping point for shipment to Buyer. ARTeSYN may choose any reasonable carrier for delivery. Tender of delivery shall be deemed made at ARTeSYN shipping point even when freight is prepaid to point or destination or ARTeSYN is required to deliver the goods to a particular destination.

 

7.     Modifications

This Agreement constitutes the entire agreement of the parties with respect to the terms and conditions of sale of the goods specified herein. No modification of this agreement shall be binding upon the parties unless in writing and signed by the party to be bound. Any terms and provisions contained in any document of Buyer which are inconsistent with the terms and conditions hereof shall not be binding on ARTeSYN and shall not be considered applicable to the sale or shipment of the goods. No agent, employee or representative of ARTeSYN other than its officers has any authority to bind ARTeSYN to any affirmation, representation or warranty concerning the goods sold under this Agreement and unless an affirmation, representation or warranty made by an agent, employee, or representative is specifically included within this Agreement, it has not formed a part of the basis of this bargain and shall not in any way be enforceable.

 

8.     Waiver

A waiver by ARTeSYN of a breach by Buyer of any provision of this Agreement shall not be deemed a waiver of future compliance with the provision of the Agreement breached.

 

9.     Assignment

No right or interest in this Agreement shall be assigned by Buyer without the written consent of ARTeSYN, and no delegation of any obligation by Buyer shall be made without the written permission of ARTeSYN. Any attempted assignment or delegation shall be wholly void and totally ineffective for all purposes unless made in conformity with this paragraph.

 

10.   Controlling Law

The validity and interpretation of this Agreement shall be governed by the laws of the State of California.

 

11.   Jurisdiction

Buyer, to the extent it may lawfully do so, hereby submits to the jurisdiction of any state or federal court located in Orange County, California as well as to the jurisdiction of all courts from which an appeal may be taken from the aforesaid courts for the purpose of any suit, action or other proceeding arising out of any of the Buyer’s obligations under or with respect to this Agreement, and the Buyer expressly waives any and all objections that Buyer may have as to jurisdiction and/or venue in any of such courts. The Buyer further agrees that it may be validly served with any legal process in connection with the foregoing by the mailing of a copy thereof by registered or certified mail at its address shown on the reverse hereof.



Terms and Conditions of Sale - ARTeSYN Biosolutions Estonia OÜ

GENERAL CONDITIONS
for the
SUPPLY OF MECHANICAL, ELECTRICAL AND ELECTRONIC PRODUCTS
Brussels, March 2012

PREAMBLE
1. These General Conditions shall apply when the parties agree In Writing or otherwise thereto. Any modifications of or deviations from them must be agreed In Writing.


DEFINITIONS
2. In these General Conditions the following terms shall have the meanings hereunder assigned to them:
- “Contract”: the agreement In Writing between the parties concerning the supply of the Product and all appendices, including agreed amendments and additions In Writing to the said documents;
- “Gross Negligence”: an act or omission implying either a failure to pay due regard to serious consequences, which a conscientious contracting party would normally foresee as likely to ensue or a deliberate disregard of the consequences of such an act or omission;
- “In Writing”: communication by a document signed by both parties or by letter, fax, electronic mail and by such other means as are agreed by the parties;
- “the Product”: the object(s) to be supplied under the Contract, including software and documentation.


PRODUCT INFORMATION
3. All information and data contained in general product documentation and price lists shall be binding only to the extent that they are by reference In Writing expressly included in the Contract.


DRAWINGS AND TECHNICAL INFORMATION
4. All drawings and technical documents relating to the Product or its manufacture submitted by one party to the other, prior or subsequent to the formation of the Contract, shall remain the property of the submitting party. Drawings, technical documents or other technical information received by one party shall not, without the consent of the other party, be used for any other purpose than that for which they were provided. They may not, without the consent of the submitting party, otherwise be used or copied, reproduced, transmitted or communicated to a third party.

5. The Supplier shall, not later than at the date of delivery, provide free of charge information and drawings which are necessary to permit the Purchaser to install, commission, operate and maintain the Product. Such information and drawings shall be supplied in the number of copies agreed upon or at least one copy of each. The Supplier shall not be obliged to provide manufacturing drawings for the Product or for spare parts.


ACCEPTANCE TESTS
6. Acceptance tests provided for in the Contract shall unless otherwise agreed, be carried out at the place of manufacture during normal working hours.
If the Contract does not specify the technical requirements, the tests shall be carried out in accordance with general practice in the appropriate branch of industry concerned in the country of manufacture.

7. The Supplier shall notify the Purchaser In Writing of the acceptance tests in sufficient time to permit the Purchaser to be represented at the tests. If the Purchaser is not represented, the test report shall be sent to the Purchaser and shall be accepted as accurate.

8. If the acceptance tests show the Product not to be in accordance with the Contract, the Supplier shall without delay remedy any deficiencies in order to ensure that the Product complies with the Contract. New tests shall then be carried out at the Purchaser’s request unless the deficiency was insignificant.

9. The Supplier shall bear all costs for acceptance tests carried out at the place of manufacture. The Purchaser shall, however, bear all traveling and living expenses for his representatives in connection with such tests.


DELIVERY. PASSING OF RISK
10. Any agreed trade term shall be construed in accordance with the INCOTERMS® in force at the formation of the Contract. If no trade term has been specifically agreed, the delivery shall be Free Carrier (FCA) at the place named by the Supplier. If in the case of delivery Free Carrier, the Supplier, at the request of the Purchaser, undertakes to send the Product to its destination, the risk will pass not later than when the Product is handed over to the first carrier.
Partial delivery shall not be permitted unless otherwise agreed.


TIME FOR DELIVERY. DELAY
11. If the parties, instead of specifying the date for delivery, have specified a period of time within which delivery shall take place, such period shall start to run as soon as the Contract is entered into and all agreed preconditions to be fulfilled by the Purchaser have been satisfied, such as official formalities, payments due at the formation of the Contract and securities.

12. If the Supplier anticipates that he will not be able to deliver the Product at the time for delivery, he shall forthwith notify the purchaser thereof In Writing, stating the reason and, if possible, the time when delivery can be expected. If the Supplier fails to give such notice, the Purchaser shall be entitled to compensation for any additional costs which he incurs and which he could have avoided had he received such notice.

13. If delay in delivery is caused by any of the circumstances mentioned in Clause 41, by an act or omission on the part of the Purchaser, including suspension under Clauses 21 and 44, or any other circumstances attributable to the Purchaser, the Supplier shall be entitled to extend the time for delivery by a period which is necessary having regard to all the circumstances of the case. This provision shall apply regardless of whether the reason for the delay occurs before or after the agreed time for delivery.

14. If the Product is not delivered at the time for delivery, the Purchaser shall be entitled to liquidated damages from the date on which delivery should have taken place. The liquidated damages shall be payable at a rate of 0.5 percent of the purchase price for each commenced week of delay. The liquidated damages shall not exceed 7.5 percent of the purchase price. If only part of the Product is delayed, the liquidated damages shall be calculated on that part of the purchase price which is attributable to such part of the Product as cannot in consequence of the delay be used as intended by the parties. The liquidated damages shall become due at the Purchaser’s demand In Writing but not before delivery has been completed or the Contract is terminated under Clause 15. The Purchaser shall forfeit his right to liquidated damages if he has not lodged a claim In Writing for such damages within six months after the time when delivery should have taken place.

15. If the delay in delivery is such that the Purchaser is entitled to maximum liquidated damages under Clause 14 and if the Product is still not delivered, the Purchaser may In Writing demand delivery within a final reasonable period which shall not be less than one week. If the Supplier does not deliver within such final period and this is not due to any circumstances which are attributable to the Purchaser, then the Purchaser may by notice In Writing to the Supplier terminate the Contract in respect of such part of the Product as cannot in consequence of the Supplier’s failure to deliver be used as intended by the parties. If the Purchaser terminates the Contract he shall be entitled to compensation for the loss he suffers as a result of the Supplier’s delay, including any consequential and indirect loss. The total compensation, including the liquidated damages which are payable under Clause 14, shall not exceed 15 percent of that part of the purchase price which is attributable to the part of the Product in respect of which the Contract is terminated. The Purchaser shall also have the right to terminate the Contract by notice In Writing to the Supplier, if it is clear from the circumstances that there will occur a delay in delivery which, under Clause 14, would entitle the Purchaser to maximum liquidated damages. In case of termination, for this reason, the Purchaser shall be entitled to maximum liquidated damages and
compensation under the third paragraph of this Clause 15.

16. Liquidated damages under Clause 14 and termination of the Contract with limited compensation under Clause 15 shall be the only remedies available to the Purchaser in case of delay on the part of the Supplier. All other claims against the Supplier based on such delay shall be excluded, except where the Supplier has been guilty of Gross Negligence.

17. If the Purchaser anticipates that he will be unable to accept delivery of the Product at the time for delivery, he shall forthwith notify the Supplier In Writing thereof, stating the reason and, if possible, the time when he will be able to accept delivery. If the Purchaser fails to accept delivery at the time for delivery, he shall nevertheless pay any part of the purchase price which becomes due at the time for delivery, as if delivery had taken place at the time for delivery. The Supplier shall arrange for storage of the Product at the risk and expense of the Purchaser. The Supplier shall also, if the Purchaser so requires, insure the Product at the Purchaser’s expense.

18. Unless the Purchaser’s failure to accept delivery is due to any such circumstance as mentioned in Clause 41, the Supplier may by notice In Writing require the Purchaser to accept delivery within a final reasonable period. If for any reason which is not attributable to the Supplier, the Purchaser fails to accept delivery within such period, the Supplier may by notice In Writing terminate the Contract in whole or in part. The Supplier shall then be entitled to compensation for the loss he suffers by reason of the Purchaser’s default, including any consequential and indirect loss. The compensation shall not exceed that part of the purchase price which is attributable to that part of the Product in respect of which the Contract is terminated.

PAYMENT
19. Payment shall be made within 30 days after the date of the invoice. Unless otherwise agreed, the purchase price shall be paid with one third at the formation of the Contract and one third when the Supplier notifies the Purchaser that the Product, or the essential part of it, is ready for delivery. The remaining part of the purchase price shall be paid when the entire Product is delivered.

20. Whatever the means of payment used, payment shall not be deemed to have been effected before the Supplier’s account has been irrevocably credited for the amount due.

21. If the Purchaser fails to pay by the stipulated date, the Supplier shall be entitled to interest from the day on which payment was due and to compensation for recovery costs. The rate of interest shall be as agreed between the parties or otherwise 8 percentage points above the rate of the main refinancing facility of the European Central Bank. The compensation for recovery costs shall be 1 percent of the amount for which interest for late payment becomes due. In case of late payment and in case the Purchaser fails to give an agreed security by the stipulated date the Supplier may, after having notified the Purchaser In Writing, suspend his performance of the Contract until he receives payment or, where appropriate until the Purchaser gives the agreed security. If the Purchaser has not paid the amount due within three months the Supplier shall be entitled to terminate the Contract by notice In Writing to the Purchaser and, in addition to the interest and compensation for recovery costs according to this Clause, to claim compensation for the loss he incurs. Such compensation shall not exceed the agreed purchase price.


RETENTION OF TITLE
22. The Product shall remain the property of the Supplier until paid for in full to the extent that such retention of title is valid under the relevant law. The Purchaser shall at the request of the Supplier assist him in taking any measures necessary to protect the Supplier’s title to the Product.
The retention of title shall not affect the passing of risk under Clause 10.


LIABILITY FOR DEFECTS
23. Pursuant to the provisions of Clauses 24-39, the Supplier shall remedy any defect or nonconformity (hereinafter termed defect(s)) resulting from faulty design, materials or workmanship.

24. The Supplier shall not be liable for defects arising out of materials provided or a design stipulated or specified by the Purchaser.

25. The Supplier shall only be liable for defects which appear under the conditions of operation provided for in the Contract and under proper use of the Product.

26. The Supplier shall not be liable for defects caused by circumstances, which arise after the risk has passed to the Purchaser, e.g. defects due to faulty maintenance, incorrect installation or faulty repair by the Purchaser or to alterations carried out without the Supplier’s consent In Writing. The Supplier shall neither be liable for normal wear and tear nor for deterioration.

27. The Supplier’s liability shall be limited to defects which appear within a period of one year from delivery. If the use of the Product exceeds that which is agreed, this period shall be reduced proportionately.

28. When a defect in a part of the Product has been remedied, the Supplier shall be liable for defects in the repaired or replaced part under the same terms and conditions as those applicable to the original Product for a period of one year. For the remaining parts of the Product, the period mentioned in Clause 27 shall be extended only by a period equal to the period during which and to the extent that the Product could not be used as a result of the defect.

29. The Purchaser shall without undue delay notify the Supplier In Writing of any defect which appears. Such notice shall under no circumstances be given later than two weeks after the expiry of the period given in Clause 27 or the extended period(s) under Clause 28, where applicable. The notice shall contain a description of the defect. If the Purchaser fails to notify the Supplier In Writing of a defect within the time limits set forth in the first paragraph of this Clause, he shall lose his right to have the defect remedied. Where the defect is such that it may cause damage, the Purchaser shall immediately inform the Supplier In Writing. The Purchaser shall bear the risk of damage to the Product resulting from his failure so to notify. The Purchaser shall take reasonable measures to minimize damage and shall in that respect comply with instructions of the Supplier.

30. On receipt of the notice under Clause 29 the Supplier shall at his own cost remedy the defect without undue delay, as stipulated in Clauses 23-39. The time for remedial work shall be chosen in order not to interfere unnecessarily with the Purchaser’s activities. Repair shall be carried out at the place where the Product is located unless the Supplier deems it more appropriate that the Product is sent to him or a destination specified by him. If the defect can be remedied by replacement or repair of a defective part and if dismantling and re-installation of the part do not require special knowledge, the Supplier may demand that the defective part is sent to him or a destination specified by him. In such case, the Supplier shall have fulfilled his obligations in respect of the defect when he delivers a duly repaired part or a part in replacement to the Purchaser.

31. The Purchaser shall at his own expense provide access to the Product and arrange for any intervention in equipment other than the Product, to the extent that this is necessary to remedy the defect.

32. Unless otherwise agreed, necessary transport of the Product or parts thereof to and from the Supplier in connection with the remedying of defects for which the Supplier is liable shall be at the risk and expense of the Supplier. The Purchaser shall follow the Supplier’s instructions regarding such transport.

33. Unless otherwise agreed, the Purchaser shall bear any additional costs which the Supplier incurs for remedying the defect caused by the Product being located in a place other than the destination stated at the formation of the Contract for the Supplier’s delivery to the Purchaser or – if no destination has been stated – the place of delivery.

34. Defective parts which have been replaced shall be made available to the Supplier and shall be his property.

35. If the Purchaser has given such notice as mentioned in Clause 29 and no defect is found for which the Supplier is liable, the Supplier shall be entitled to compensation for the costs he incurs as a result of the notice.

36. If the Supplier does not fulfill his obligations under Clause

30, the Purchaser may by notice In Writing fix a final reasonable period for completion of the Supplier’s obligations, which shall not be less than one week. If the Supplier fails to fulfill his obligations within such final period, the Purchaser may himself undertake or employ a third party to undertake necessary repair work at the risk and expense of the Supplier. Where successful repair work has been undertaken by the Purchaser or a third party, reimbursement by the Supplier of reasonable costs incurred by the Purchaser shall be in full settlement of the Supplier’s liabilities for the said defect.

37. Where the Product has not been successfully repaired, as stipulated under Clause 36,
a) the Purchaser shall be entitled to a reduction of the purchase price in proportion to the reduced value of the Product, provided that under no circumstances shall such reduction exceed 15 percent of the purchase price, or
b) where the defect is so substantial as to significantly deprive the Purchaser of the benefit of the Contract as regards the Product or a substantial part of it, the Purchaser may terminate the Contract by notice In Writing to the Supplier in respect of such part of the Product as cannot in consequence of the defect be used as intended by the parties. The Purchaser shall then be entitled to compensation for his loss, costs, and damages up to a maximum of 15 percent of that part of the purchase price which is attributable to the part of the Product in respect of which the Contract is terminated.

38. Notwithstanding the provisions of Clauses 23-37, the Supplier shall not be liable for defects in any part of the Product for more than one year from the end of the liability period referred to in Clause 27 or from the end of any other liability period agreed upon by the parties.

39. Save as stipulated in Clauses 23-38, the Supplier shall not be liable for defects. This applies to any loss the defect may cause including loss of production, loss of profit and other indirect loss. This limitation of the Supplier’s liability shall not apply if he has been guilty of Gross Negligence.


ALLOCATION OF LIABILITY FOR DAMAGE CAUSED BY THE PRODUCT
40. The Supplier shall not be liable for any damage to property caused by the Product after it has been delivered and whilst it is in the possession of the Purchaser. Nor shall the Supplier be liable for any damage to products manufactured by the Purchaser or to products of which the Purchaser’s products form a part. If the Supplier incurs liability towards any third party for such damage to property as described in the preceding paragraph, the Purchaser shall indemnify, defend and hold the Supplier harmless. If a claim for damage as described in this Clause is lodged
by a third party against one of the parties, the latter party shall forthwith inform the other party thereof In Writing. The Supplier and the Purchaser shall be mutually obliged to let themselves be summoned to the court or arbitral tribunal examining claims for damages lodged against one of them on the basis of damage allegedly caused by the Product. The liability between the Supplier and the Purchaser shall, however, be settled in accordance with Clause 46. The limitation of the Supplier’s liability in the first paragraph of this Clause shall not apply where the Supplier has been guilty of Gross Negligence.


FORCE MAJEURE
41. Either party shall be entitled to suspend performance of his obligations under the Contract to the extent that such performance is impeded or made unreasonably onerous by Force Majeure, meaning any of the following circumstances: industrial disputes and any other circumstance beyond the control of the parties such as fire, war, extensive military mobilization, insurrection, requisition, seizure, embargo, restrictions in the use of power, currency and export restrictions, epidemics, natural disasters, extreme natural events, terrorist acts and defects or delays in deliveries by sub-contractors caused by any such circumstance referred to in this Clause. A circumstance referred to in this Clause whether occurring prior to or after the formation of the Contract shall give a right to suspension only if its effect on the performance of the Contract could not be foreseen at the time of the formation of the Contract.

42. The party claiming to be affected by Force Majeure shall notify the other party In Writing without delay on the intervention and on the cessation of such circumstance. If a party fails to give
such notice, the other party shall be entitled to compensation for any additional costs which he incurs and which he could have avoided had he received such notice. If Force Majeure prevents the Purchaser from fulfilling his obligations, he shall compensate the Supplier for expenses incurred in securing and protecting the Product.

43. Regardless of what might otherwise follow from these General Conditions, either party shall be entitled to terminate the Contract by notice In Writing to the other party if performance of the Contract is suspended under Clause 41 for more than six months.


ANTICIPATED NON-PERFORMANCE
44. Notwithstanding other provisions in these General Conditions regarding suspension, each party shall be entitled to suspend the performance of his obligations under the Contract, where it is clear from the circumstances that the other party is not going to perform his obligations. A party suspending his performance of the Contract shall forthwith notify the other party thereof In Writing.


CONSEQUENTIAL LOSSES
45. Save as otherwise stated in these General Conditions there shall be no liability for either party towards the other party for loss of production, loss of profit, loss of use, loss of contracts or for any other consequential or indirect loss whatsoever.


DISPUTES AND APPLICABLE LAW
46. All disputes arising out of or in connection with the Contract shall be finally settled under the Rules of Arbitration of the International Chamber of Commerce by one or more arbitrators appointed in accordance with the said Rules.

47. The Contract shall be governed by the substantive law of the Supplier’s country.

This is an Orgalime publication. Orgalime represents the mechanical, electrical, electronic and metalworking industries in Europe.
All rights reserved ©
Editeur responsable: Adrian Harris, Director General
ORGALIME – The European Engineering Industries Association
Diamant Building, Boulevard A Reyers 80, B–1030 Brussels
Tel: +32 2 706 82 35 – Fax: +32 2 706 82 50 – secretariat@orgalime.org – www.orgalime.org
This document is used under sublicense from Teknikföretagen. It may not be stored on internal or external networks.